TERMS OF SERVICE

Effective Date: January 1st, 2026

Welcome to Four Leaf Home Integration (“Company,” “we,” “our,” or “us”). These Terms of Service (“Terms”) govern your use of our website located at www.fourleafhomeintegration.com and any related services provided by us.

By accessing or using this website, submitting information through our contact forms, requesting a quote, or engaging our services, you agree to these Terms. If you do not agree, please do not use this website.

1. SERVICES

Four Leaf Home Integration provides low-voltage installation and related services, including but not limited to:

Security camera systems
Smart home systems
Audio/video installations
Structured cabling
Networking equipment
Access control systems
Commercial low-voltage installations
Residential low-voltage installations

All services are subject to availability, project scope, site conditions, scheduling, and applicable laws or building codes.

2. WEBSITE INFORMATION

The information provided on this website is for general informational purposes only. While we strive to keep information accurate and current, we do not guarantee the completeness, accuracy, reliability, or availability of any content, pricing, specifications, or product information displayed on the website.

We reserve the right to modify, discontinue, or update website content or services at any time without notice.

3. ESTIMATES AND PROJECT SCOPE

Any quotes, estimates, or project timelines provided through this website, by email, phone, or in person are non-binding unless otherwise stated in a signed agreement.

Project pricing may change due to:

Changes in project scope
Hidden site conditions
Material cost increases
Additional labor requirements
Permit or code compliance requirements
Customer-requested modifications

Additional work outside the agreed scope may result in additional charges.

4. SCHEDULING AND PROJECT DELAYS

Project timelines are estimates only and are not guaranteed.

We are not responsible for delays caused by:

Weather
Supply chain shortages
Manufacturer delays
Utility interruptions
Permit processing
Site readiness issues
Customer scheduling conflicts
Third-party contractor delays
Events beyond our reasonable control

5. THIRD-PARTY PRODUCTS AND SERVICES

Our installations may involve third-party hardware, software, cloud platforms, mobile applications, or networking services provided by manufacturers or vendors.

We do not control and are not responsible for:

Manufacturer defects
Software bugs
Internet outages
Cloud service interruptions
Mobile application functionality
Product discontinuation
Third-party security vulnerabilities
Firmware or software updates issued by manufacturers

Manufacturer warranties, if applicable, are provided solely by the manufacturer.

6. SECURITY SYSTEM DISCLAIMER

Client understands and agrees that no security, surveillance, monitoring, or smart-home system is guaranteed to prevent theft, intrusion, fire, vandalism, property damage, injury, or other losses.

Installed systems are intended only to reduce certain risks and provide monitoring capabilities. System failures may occur due to power outages, internet interruptions, equipment malfunction, environmental conditions, tampering, or other factors outside our control.

[Company Name] shall not be liable for any losses, damages, injuries, or claims related to the failure or performance of any installed system.

7. CUSTOMER RESPONSIBILITIES

Customers agree to:

Provide safe and reasonable access to the property
Ensure availability of electrical power and internet connectivity where required
Obtain any necessary permissions or approvals
Provide accurate project information
Secure pets or hazardous conditions before installation
Inform us of known site hazards or construction limitations

We reserve the right to postpone or refuse service if unsafe or unsuitable conditions exist.

8. PAYMENTS

Payment terms may be outlined in separate estimates, invoices, or service agreements.

Unless otherwise agreed in writing:

Deposits may be required before work begins
Final payment is due upon completion of work
Late payments may incur additional fees
Unpaid balances may result in suspension of services or collections activity

Ownership of installed equipment may remain with [Company Name] until payment is received in full where permitted by law.

9. WARRANTIES

We may provide a limited workmanship warranty for installations performed by our technicians. Warranty details, duration, and limitations may be provided separately in writing.

Warranty coverage does not apply to:

Misuse or abuse
Unauthorized modifications
Power surges or lightning damage
Internet or ISP failures
Water damage
Natural disasters
Customer network issues
Third-party equipment failures
Damage caused by other contractors or service providers

EXCEPT AS EXPRESSLY PROVIDED, ALL SERVICES ARE PROVIDED “AS IS” WITHOUT WARRANTIES OF ANY KIND, EXPRESS OR IMPLIED.

10. LIMITATION OF LIABILITY

TO THE MAXIMUM EXTENT PERMITTED BY LAW, FOUR LEAF HOME INTEGRATION SHALL NOT BE LIABLE FOR ANY INDIRECT, INCIDENTAL, SPECIAL, CONSEQUENTIAL, OR PUNITIVE DAMAGES, INCLUDING LOSS OF DATA, LOSS OF PROFITS, LOSS OF BUSINESS, PROPERTY DAMAGE, OR SECURITY INCIDENTS ARISING OUT OF OR RELATED TO THE USE OF OUR WEBSITE OR SERVICES.

OUR TOTAL LIABILITY FOR ANY CLAIM SHALL NOT EXCEED THE TOTAL AMOUNT PAID TO US FOR THE SPECIFIC SERVICES GIVING RISE TO THE CLAIM.

11. INDEMNIFICATION

You agree to indemnify and hold harmless Four Leaf Home Integration, its owners, employees, contractors, and affiliates from any claims, damages, liabilities, costs, or expenses arising from:

Your misuse of our services
Your violation of these Terms
Site conditions at your property
Unauthorized modifications to installed systems
Your violation of applicable laws or regulations

12. INTELLECTUAL PROPERTY

All website content, including logos, branding, graphics, text, photos, videos, and designs, is the property of Four Leaf Home Integration unless otherwise stated.

You may not copy, reproduce, distribute, or use our content without prior written permission.

13. PRIVACY

Your use of this website is also governed by our Privacy Policy.

We may collect personal information submitted through:

Website contact forms
Quote request forms
Facebook or social media lead forms
Phone calls or email communications

Information collected may include your name, email address, phone number, address, and project details.

We use this information to respond to inquiries, provide estimates, communicate regarding services, and improve our business operations.

14. THIRD-PARTY LINKS

This website may contain links to third-party websites or services. We are not responsible for the content, policies, or practices of third-party websites.

Use of third-party services is at your own risk.

15. TERMINATION

We reserve the right to refuse service, terminate communications, or restrict access to the website at our sole discretion, including for misuse, abusive conduct, fraudulent activity, or violation of these Terms.

16. GOVERNING LAW

These Terms shall be governed by and interpreted in accordance with the laws of the State of New York, without regard to conflict of law principles.

Any disputes arising under these Terms shall be resolved in the courts located within the State of New York.

17. CHANGES TO THESE TERMS

We reserve the right to update or modify these Terms at any time without prior notice.

Updated versions will be posted on this page with a revised effective date. Continued use of the website constitutes acceptance of the updated Terms.

18. CONTACT INFORMATION

Four Leaf Home Integration
2 Bishop Dr
Poughkeepsie, NY, 12603
(203) 885-4300
info@fourleafhomeintegration.com
www.fourleafhomeintegration.com

If you have any questions regarding these Terms, please contact us using the information above.